GENERAL CONDITIONS OF SUBCONTRACT – LONG FORM
GENERAL CONDITIONS OF SUBCONTRACT – LONG FORMV4.0 11/16Wiley & Co Pty Ltd ABN 40 010 604 869Copyright licence held by Wiley. This document must not be reproduced without the express authority of Wiley. Long Form - V4.0 11/16
TABLE OF CONTENTSSubcontract general conditions . 11Main obligations . 1Subcontractor’s main obligations . 1Subcontractor’s warranties . 1Subcontractor’s indemnity for breach of warranties . 2Subcontractor's acknowledgement about completion of the subcontract works. 2Wiley’s main obligations . 22Administration. 3Wiley’s project manager as certifier . 3Subcontractor must comply with instructions from Wiley . 3Supervision by Wiley . 3Subcontractor’s supervision. 3Wiley may exclude the subcontractor’s representative, foreman or workers . 4Sub-subcontracting . 4Subcontractor's project personnel. 4Site meetings. 5Subcontractor’s financial capability . 53Constitution of the subcontract and documents generally . 5Documents constituting the subcontract . 5The head contract . 6Documents from Wiley . 6Subcontractor to supply documents . 6Shop drawings . 7Resolution of discrepancies . 74The subcontract works . 7Construction in accordance with subcontract . 7Proposed variations to subcontract works . 7Wiley may instruct variations to the subcontract works . 8Day work . 9Provisional work . 9Materials and standard of work . 10Subcontractor is responsible for verifying sizes, dimensions and set out . 10Co-ordination of fixings, penetrations etc. . 11Subcontractor acceptance of design (for certification) and prior work . 12Subcontractor must rectify all defects in the subcontract works . 13Defects rectification period . 13Acceptance of defective work. 14Protection of the subcontract works and damage. 14Reinstatement of damaged subcontract works . 14Damage to other works . 15Manufacturer's recommendations, standards and codes . 15Warranties, manuals, as-built drawings. 15Proprietary brands . 16Commissioning . 16Notices and fees . 16Compliance with legislative requirements. 17Copyright licence held by Wiley. This document must not be reproduced without the express authority of Wiley. Long Form - V4.0 11/16i
Examination and testing required by the subcontractor . 17Further testing required by Wiley . 17Results of tests . 17Costs of further testing instructed by Wiley . 18Unobtainable materials. 18Urgent protection . 18Separable portions . 18Completion of the subcontract works . 195General requirements for subcontract works . 19Protection of people and property . 19Industrial relations . 19Workplace health and safety and safety precautions. 20Environmental Management . 21Quality plan . 21Wages, employee benefits etc. . 22Codes of Practice for the Construction Industry . 226Design (if applicable). 22Design development . 22Liaison with Wiley . 22Approval of design documents by Wiley. 23Approval does not relieve subcontractor from responsibility . 23Intellectual property – consultants to the subcontractor . 23Moral rights . 247The site . 24Description . 24Access for other subcontractors . 24Access to the site for Wiley . 24Subcontractor accepts site conditions . 25Claims for unanticipated conditions limited by the head contract. 25Hazardous Substances . 25Adjoining or neighbouring buildings . 26Use of site by subcontractor . 26Finding of minerals, fossils and relics . 26Site to be clean and tidy. 26Protection of trees and plants . 26Environmental protection . 27Noise control . 27Vehicles on site . 27Entry to site . 27Site control . 27Unloading and access . 27Existing services . 27Works accommodation and amenities . 28Storage and office facilities . 28Signage . 288Site services . 28Temporary services by Wiley . 28Scaffolding. 29Additional services, including scaffold etc . 29Copyright licence held by Wiley. This document must not be reproduced without the express authority of Wiley. Long Form - V4.0 11/16ii
9Time, performance, delay and acceleration . 29Time for commencement of subcontract works . 29Subcontractor must comply with the program. 29Time for performance and completion of the subcontract works. 30Site working days and times . 30Subcontractor's failure to comply with the program . 31Extensions of time . 31Delay and disruption costs . 32Suspension . 32Acceleration – subcontractor to state costs . 32Wiley may instruct subcontractor to accelerate . 33Limitations on acceleration costs. 33Subcontractor’s liability for delay and disruption . 33General discretion for Wiley to extend time . 3410Subcontract sum, deductions and claims for adjustments . 34Subcontract sum . 34Deductions for subcontractor’s default . 34Claims for variations to the subcontract works . 35Valuation of variations and provisional work . 36Limitation on subcontractor’s right to recovery for variations . 36Claims for costs of tests instructed by Wiley . 36Claims under the head contract . 37Rise and fall . 37Bills of quantity and schedules of rates . 38GST glossary . 38Goods and services tax (GST) - subcontractor warranties . 38Adjustment of the subcontract sum for GST related tax changes . 39Wiley’s GST warranties . 39Accounting for GST payable . 39Tax invoices . 3911Pr
1.4.2 The subcontract Works constitute an essential and integral part of the head contract works. 1.4.3 The subcontract Works are required only because Wiley is obliged to perform the head contract works. 1.4.4 The subcontract works must
SUBCONTRACT TERMS AND CONDITIONS Subcontract Terms and Conditions (1/2007 ed.) Page 1 of 16 . The following Subcontract Terms and Conditions are incorporated in the Subcontract between Contractor and Subcontractor. ARTICLE1 . SUBCONTRACT DOCUMENTS . 1.1 The Pri
Appendix 4:[Subcontract Closure Certificate] herein. “SUBCONTRACT PRICE” means the sum specified in the SUBCONTRACT, as may be adjusted pursuant to the provisions of the SUBCONTRACT, to be paid to the SUBCONTRACTOR by MMHE in accordance with the provisions of the SUBCONTRACT
Dec 09, 2019 · RECEIPT OF THIS SUB-SUBCONTRACT FORM SHALL BE DEEMED ACCEPTANCE OF ALL OF THE TERMS AND CONDITIONS SET FORTH HEREIN WITH RESPECT TO THE PERFORMANCE OF THE WORK This Sub-Subcontract Agreement (this “Sub-Subcontract”, “Subcontract Agreement” or “Subcontract”) for
TONN AND BLANK CONSTRUCTION, LLC SUBCONTRACT AGREEMENT (1) SUBCONTRACT DOCUMENTS The "Subcontract Documents" for this Agreement consist of this Agreement, the Subcontract General Conditions attached hereto and incorporated herein as Exhibit A
Subcontract Review Attached is a Sample of our standard Subcontract Agreement. This Document defines our standard subcontract terms and conditions, Exhibits A and B, as well as the typical Subcontract format for all parts of this document such as, Exhibit C ,
“The Red Book Subcontract--Conditions of Subcontract for Construction for Building and Engineering Works, Designed by the Employer, First Edition 2011” (FIDIC 2011), “Conditions of Subcontract by Construction Industry Development Board CIDB,
Conditions of Subcontract for Construction Works First Edition (2018) is not expressly specified in the Subcontract Data or is not otherwise indicated in this Subcontract or its Main Contract, then the print version as commercially available
courts interpret laws, adjudicate dis-putes under laws, and at times even strike down laws as violating the fun-damental protections that the Consti-tution guarantees all Americans. At the same time, millions of Americans transact their day-to-day affairs with-out turning to the courts. They, too, rely upon the legal system. The young
