SG-IMS-SF-8413 AS 4901-1998 Subcontract Conditions V4

2y ago
20 Views
2 Downloads
424.63 KB
76 Pages
Last View : 15d ago
Last Download : 3m ago
Upload by : Lilly Kaiser
Transcription

Subcontract Conditions(Amended AS 4901-1998)Level 2, 45 Watt Street, Newcastle NSW 2300PO Box 1801, Newcastle NSW 2300DX 7808, Newcastle NSWTelephone 61 2 4911 5400 Fax 61 2 9232 1004SGO:359558SG-IMS-SF-8413/00

TABLE OF CONTENTS1.2.Interpretation and construction of Subcontract . 11.1Definitions . 11.2References . 71.3Contra Proferentem . 71.4Rights and remedies not affected . 81.5Application of this deed . 81.6Entire Agreement . 81.7Variation and Waivers in Writing. 81.8Nature of the Relationship . 81.9Joint and Several . 81.10Counterparts . 9Nature of Subcontract . 92.1Performance and payment . 92.2Bill of quantities . 92.3Priced bill of quantities . 102.4Quantities . 102.5Adjustment for actual quantities. 103.Provisional Sums . 114.Separable portions . 115.Security . 125.1Provision . 125.2Recourse. 125.3Change of security . 125.4Reduction and release . 125.5Trusts and interest. 125.6Deed of guarantee, undertaking and substitution . 136.Evidence of Subcontract . 137.Service of notices . 138.Subcontract documents . 148.1Discrepancies. 148.2Main Contractor-supplied documents . 148.3Subcontractor-supplied documents . 148.4Availability . 158.5Confidential information . 158.6Media . 158.7Main Contract . 16Moray & AgnewPage i of v1 September 2015SG-IMS-SF-8413/00

9.Assignment and secondary subcontracting . 169.1Assignment . 169.2Secondary subcontracting generally . 179.3Selected secondary subcontract work . 179.4Novation . 179.5Subcontractor's responsibility . 1810.Intellectual property rights . 1811.Legislative requirements . 1811.1Compliance . 1811.2Changes. 1811.3Work health and safety requirements . 1912.Protection of people and property. 1913.Urgent protection . 2014.Care of the work and reinstatement of damage . 2015.14.1Care of WUS . 2014.2Reinstatement . 2014.3Excepted risks . 21Damage to persons and property other than WUS. 2115.1Indemnity by Subcontractor . 2115.2Indemnity by Main Contractor. 2216.Insurance of the Subcontract Works . 2217.Public liability insurance . 2318.Insurance of employees . 2419.Inspection and provisions of insurance policies. 2419.1Proof of insurance . 2419.2Failure to produce proof of insurance . 2419.3Notices from or to insurer . 2419.4Notices of potential claims . 2519.5Settlement of claims . 2519.6Cross liability . 2520.Subcontract Superintendent . 2621.Subcontract Superintendent's Representative . 2622.Subcontractor's representative . 2623.Subcontractor's employees and secondary subcontractors. 2724.Site . 27Moray & AgnewPage ii of v1 September 2015SG-IMS-SF-8413/00

24.1Non-exclusive possession . 2724.2Access for Main Contractor and others. 2724.3Minerals, fossils and relics. 2824.4Other contractors . 2825.Latent conditions . 2926.Setting out the Subcontract Works . 3026.1Setting out . 3026.2Errors in setting out . 3026.3Care of survey marks . 3027.Cleaning up . 3128.Materials, labour and construction plant . 3129.Quality . 3230.29.1Quality of material and work . 3229.2Quality assurance . 3229.3Defective work. 3329.4Timing . 33Examination and testing. 3430.1Tests . 3430.2Covering up . 3430.3Who conducts . 3430.4Notice . 3430.5Delay . 3430.6Completion and results. 3430.7Costs . 3431.Working hours . 3532.Programming . 3533.Suspension . 3634.33.1Subcontract Superintendent's suspension . 3633.2Subcontractor's suspension. 3633.3Recommencement . 3733.4Cost . 37Time and progress . 3734.1Progress. 3734.2Notice of delay . 3734.3Claim . 3734.4Assessment. 3834.5Extension of time . 38Moray & AgnewPage iii of v1 September 2015SG-IMS-SF-8413/00

34.6Acceleration of WUS . 3834.7Practical completion . 3934.8Liquidated damages . 4034.8A Indemnity . 4034.9Bonus for early practical completion . 4134.10 Delay damages . 4135.Defects liability . 4136.Variations . 4237.38.39.36.1Directing variations . 4236.2Proposed variations. 4236.3Variations for convenience of Subcontractor . 4336.4Pricing . 43Payment. 4337.1Progress claims. 4337.2Certificates . 4437.3Unfixed plant and materials . 4437.4Final payment claim and certificate . 4537.5Interest . 4537.6Other moneys due . 4637.7Taxes . 46Payment of workers and secondary subcontractors . 4638.1Workers and secondary subcontractors . 4638.2Withholding payment . 4738.3Direct payment . 47Default or insolvency. 4739.1Preservation of other rights . 4739.2Subcontractor's default . 4839.3Main Contractor's notice to show cause . 4839.4Main Contractor's rights. 4939.5Take out . 4939.6Adjustment on completion of work taken out . 4939.7Main Contractor's default. 5039.8Subcontractor's notice to show cause . 5039.9Subcontractor's rights . 5139.10 Termination . 5139.11 Insolvency . 5140.Termination by frustration . 5241.Termination for convenience . 53Moray & AgnewPage iv of v1 September 2015SG-IMS-SF-8413/00

42.43.Notification of claims. 5442.1Communication of claims . 5442.2Liability for failure to communicate . 5442.3Subcontract Superintendent's decision . 54Dispute resolution . 5543.1Notice of dispute . 5543.2Conference . 5543.3Main contract arbitrator . 5643.4Main contract disputes affecting the Subcontract . 5643.5Summary relief . 5644.Waiver of conditions. 5645.Services and facilities . 5745.1Provision of services and facilities . 5745.2Compliance . 5745.3Additional services or facilities . 57Annexure – Part A .58Moray & AgnewPage v of v1 September 2015SG-IMS-SF-8413/00

1.INTERPRETATION AND CONSTRUCTION OF SUBCONTRACT1.1DefinitionsIn the Subcontract, except where the context otherwise requires:Item means an Item in Annexure Part A;Australian Standards means standards and codes published by Standards AustraliaInternational Limited (ABN 85 087 326 690);bill of quantities means a document named therein as a bill of quantities issued totenderers by or on behalf of the Main Contractor, stating estimated quantities of workto be carried out;certificate of practical completion has the meaning in subclause 34.7;compensable cause means:(a)any act, default or omission of the Subcontract Superintendent, the MainContractor or its consultants, agents or other contractors (not being employedby the Subcontractor);(b)any act, default or omission of the Superintendent, the Principal or itsconsultants, agents or other contractors (not being employed by theSubcontractor); or(c)those listed in Item 29;comp

1 September 2015SG-IMS-SF-8413 AS 4901-1998 Subcontract Conditions v4.docx 1. INTERPRETATION AND CONSTRUCTION OF SUBCONTRACT 1.1 Definitions In the Subcontract , except where the context otherwise requires: Item means an Item in Annexure Part A; Australian Standards m

Related Documents:

IMS-100: Introduction to IMS . IMS-100 December 2008 Page 4 of 81 . Preface . Welcome to IMS-100: Introduction to IMS in Ontario. This Self-Directed course is designed to teach you the basic functions, concepts, and principles of the Incident Management System (IMS). At the end of this course you will be aware of the major

IBM IMS Fast Path Online Tools IMS Fast Path Online Tools IBM IMS Hardware Data Compression-Extended IMS Hardware Data Compression-Extended IBM IMS High Availability Large Database (HALDB) Conversion Aid for z/OS IBM IMS HALDB Conversion Aid IBM IMS High Performance Change

region. IMS determines, from DBD, that a Segment Edit/Compression exit is required, so IMS loads the exit. 2. IMS retrieves encrypted segment from the database. 3. IMS then calls the exit and passes it the encrypted segment. The exit invokes ICSF services, which passes the user-defined data encryption key label (provided by exit) and the

IMS Open Transaction Manager Access (OTMA) is a transaction-based, connectionless client/server protocol. By using OTMA, each client (z/OS application) can s ubmit transactions to IMS or issue IMS commands and receive output from IMS application programs and from IMS itself.

IMS service ability open to 3rd party and internet for more flexible service and application Service engine open to 3rd party and Internet ICT application SIP IAD、SIP AG access to IMS IMS support for PSTN/ISDN Emulation/Simulation service AGCF and mAGCF access to IMS Network evolution Video conference/video telephony

1.3 IMS-based Power Stage Design 1.3.1 IMS Board thermal design An IMS board assembly uses metal as the PCB core, to which a dielectric layer and copper foil layers are bonded. The metal PCB core is often aluminum. The copper foil layers can be single or doublesided. An - IMS board offers superior thermal conductivity to standard FR4 PCB.

service corresponds to an IMS se rver transaction. Service request s issued by clients in the Oracle Tuxedo system are routed through the TMA TCP Gateway to the TMA TCP for IMS gateway for processing by the appropriate IMS server transaction. Similarly, the configuration definition in the TMA TCP for IMS gateway maps local service

Academic writing is often a highly problematic but always potentially trans-formational activity. Despite the great diversity within and between different academic disciplines, several common themes are associated with the experi-ence of writing in academia. It is often encountered as a process that is full of paradoxes. This book aims to identify and explore those common themes and to help .